FAR 42.1302 — Suspension of work
Regulatory text. Not legal advice.
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.
Source: eCFR • Pulled 2026-04-16